Log in or register
Share on LinkedInShare on LinkedIn

ARTICLE · 05 AUGUST 2021

Legal Developments In Construction Law: July 2021

Mayer Brown
Mayer Brown
Contributor
Mayer Brown

Mayer Brown

Mayer Brown is a leading international law firm positioned to represent the world’s major...

View firm profile
Explore more from Mayer Brown

A contract for works to modernise a 1970s house in Cheshire had no contract administrator. There were a number of variations and the works were delayed but there was no extension of ...

United KingdomGovernment, Public Sector
Mayer Brown
Mayer Brown
Author LinkedIn connections

1. Failure to complete in a reasonable time - could that be a repudiation?

A contract for works to modernise a 1970s house in Cheshire had no contract administrator. There were a number of variations and the works were delayed but there was no extension of time mechanism in the contract. Among other issues, the court had to decide the parties' competing claims as to repudiation. The builder said that the homeowner's refusal to confirm that it was allowed access was repudiatory, and that it accepted this repudiatory breach. The homeowner claimed, however, that the builder was in repudiatory breach of its obligation to complete the works within a reasonable time, having effectively given up on the works, and that she accepted the repudiation.

We operate a free-to-view policy, asking only that you register in order to read all of our content. Please login or register to view the rest of this article.

Register for freeORLog in

Visit us at mayerbrown.com

Mayer Brown is a global services provider comprising associated legal practices that are separate entities, including Mayer Brown LLP (Illinois, USA), Mayer Brown International LLP (England & Wales), Mayer Brown (a Hong Kong partnership) and Tauil & Chequer Advogados (a Brazilian law partnership) and non-legal service providers, which provide consultancy services (collectively, the “Mayer Brown Practices”). The Mayer Brown Practices are established in various jurisdictions and may be a legal person or a partnership. PK Wong & Nair LLC (“PKWN”) is the constituent Singapore law practice of our licensed joint law venture in Singapore, Mayer Brown PK Wong & Nair Pte. Ltd. Details of the individual Mayer Brown Practices and PKWN can be found in the Legal Notices section of our website. “Mayer Brown” and the Mayer Brown logo are the trademarks of Mayer Brown.

© Copyright 2024. The Mayer Brown Practices. All rights reserved.

This Mayer Brown article provides information and comments on legal issues and developments of interest. The foregoing is not a comprehensive treatment of the subject matter covered and is not intended to provide legal advice. Readers should seek specific legal advice before taking any action with respect to the matters discussed herein.

View source

Related Articles

Legal Intelligence Newsletters: sign up for the latest legal and regulatory news on your chosen topics

Read more about

See more popular content from

Article

Sanctions: Fortnightly Summary

The UK government has significantly expanded its sanctions framework targeting Russia, introducing measures against individuals and entities involved in military supply chains, energy sectors, cryptocurrency networks, and alleged human rights violations. These developments reflect an evolving enforcement landscape with new powers, increased scrutiny of sanctions evasion, and landmark legal clarifications affecting businesses operating in sanctioned jurisdictions.
European UnionGovernment, Public Sector
BCL Solicitors LLP
BCL Solicitors LLP
Article

Budget Tracker (2026)

The Chancellor of the Exchequer faces the formidable challenge of delivering his first Budget amid economic headwinds, geopolitical instability, and a wave of ambitious government promises. With GDP growth forecast at just 1.1%, inflation at 3.4%, and public sector net borrowing exceeding £115 billion, can he balance fiscal responsibility with pledges to avoid raising Income Tax, National Insurance, or VAT while funding increased defence spending and social care reforms?
United KingdomGovernment, Public Sector
Travers Smith LLP
Travers Smith LLP
Article

Investing In Infrastructure: When Public Policy Meets Private Capital

Governments across the UK and Europe have announced ambitious infrastructure programmes they cannot fund alone, creating significant opportunities for private capital. As public authorities shift from subsidy-based models to regulatory reform, investors must navigate an increasingly complex web of concurrent regulatory regimes - from merger control and national security screening to data protection and PFI handback obligations - to successfully deploy capital in this evolving landscape.
European UnionGovernment, Public Sector
Macfarlanes LLP
Macfarlanes LLP
Article

Foreign Direct Investment (FDI) And National Security Screening

Angela Gregson of Weightmans and Sean Ryan of Whitney Moore compare Ireland's new foreign direct investment screening regime with the UK's established National Security and Investment Act, examining when notification is required, key procedural differences, and practical steps to navigate both frameworks. The analysis draws on recent annual reports to reveal how these regimes are operating in practice and what reforms are on the horizon.
United KingdomGovernment, Public Sector
Weightmans LLP
Weightmans LLP
Article

DOL Announces Enforcement Actions Against Employers In H-1B And PERM Fraud Probe

The Trump Administration has launched an unprecedented enforcement action suspending permanent labor certification processing for eight major employers, linking immigration sponsorship to layoff histories and recruitment practices. This development signals a fundamental shift in how the government evaluates employer access to H-1B and green card programs, with investigations already underway and subpoenas served.
United StatesEmployment and HR
Mayer Brown
Mayer Brown
Article

Trump Administration Announces New Enforcement Actions Against Employers In H-1B And PERM Fraud Probes

The Trump Administration has launched an unprecedented investigation into H-1B visa and PERM labor certification programs, with the Department of Labor's Office of Inspector General issuing dozens of subpoenas and suspending employers' ability to process applications. Federal agencies are deploying new enforcement tools including whistleblower programs and criminal prosecution threats...
United StatesImmigration
Mayer Brown
Mayer Brown
Article

Landmark DoorDash Settlement Confirms NYC DCWP’s Aggressive Enforcement Posture

New York City's Department of Consumer and Worker Protection secured a landmark $131.5 million settlement with DoorDash, marking the largest worker settlement in the city's history and the largest involving food delivery workers nationwide. The agreement provides over $115 million in direct compensation to more than 260,000 delivery workers who were underpaid, unpaid, or paid late, while establishing a comprehensive three-year compliance monitoring program.
United StatesEmployment and HR
Mayer Brown
Mayer Brown
Article

Contracting Opportunities And Challenges For Emerging Agentic AI Companies

Emerging providers of AI agents face unique contracting challenges as autonomous AI tools evolve beyond traditional SaaS models. This analysis examines critical issues in defining agent authority, structuring pricing models, calibrating warranties, and navigating regulatory uncertainty. How should providers balance customer expectations with the unpredictable nature of autonomous AI systems?
United StatesMedia, Telecoms, IT, Entertainment
Mayer Brown
Mayer Brown
Article

SEC Staff Statement On Fair Value Measurement And Disclosure Considerations For Private Assets

The SEC Staff has issued new guidance addressing fair value measurement and disclosure practices for private credit and other illiquid assets held by registered funds and business development companies. As private credit portfolios have grown nearly 60% since 2020, reaching $270 billion, regulators emphasize the critical importance of robust valuation methodologies, transparent disclosure of significant judgments, and careful application of accounting standards when market prices are unavailable.
United StatesAccounting and Audit
Mayer Brown
Mayer Brown