Log in or register
Share on LinkedInShare on LinkedIn

ARTICLE · 26 MARCH 2021

Ontario Superior Court Endorses Practical Definition Of Concurrent Delay

Gowling WLG
Gowling WLG
Contributor
Gowling WLG

Gowling WLG

The firm The firm’s lawyers speak English, French, Russian and Ukrainian. The firm’s client base...

View firm profile
Explore more from Gowling WLG

Construction delay claims are notoriously complex, particularly when determining responsibility for concurrent delays. The Ontario Superior Court provided new direction for assessing concurrent...

CanadaReal Estate and Construction
Sahil Shoor
Sahil Shoor
Tristan Neill
Tristan Neill
Author LinkedIn connections

Construction delay claims are notoriously complex, particularly when determining responsibility for concurrent delays. The Ontario Superior Court provided new direction for assessing concurrent delay in its January 18, 2021 decision in Schindler Elevator Corporation v. Walsh Construction Company of Canada (2021 ONSC 283).1

This case arose out of the construction of a new hospital in downtown Toronto by a partnership between Walsh Construction Company of Canada and Bondfield Construction Company Limited ("WBP") for the Women's College Hospital Capital Redevelopment Project (the "Project").   Schindler Elevator Corporation ("Schindler") was hired as the elevator subcontractor. 

We operate a free-to-view policy, asking only that you register in order to read all of our content. Please login or register to view the rest of this article.

Register for freeORLog in

The content of this article is intended to provide a general guide to the subject matter. Specialist advice should be sought about your specific circumstances.

View source

Related Articles

Legal Intelligence Newsletters: sign up for the latest legal and regulatory news on your chosen topics

Read more about

Related Comparative Guides

See more popular content from

Article

Ontario’s Mandatory Annual Holdback Release Starts In 2027: What Owners And Contractors Need To Know

Starting in 2027, all Ontario project owners with contracts entered into on or after January 1, 2026, and most owners with contracts dating back to July 1, 2018, must start releasing statutory holdback to their contractors on an annual basis. This requirement is the latest in a series of construction payment reforms under Ontario’s Construction Act. It replaces the traditional model of retaining holdback until substantial performance. Owners and contractors who fail to comply with the notice and payment timelines face exposure to interest claims, payment disputes, and adjudication proceedings.
CanadaReal Estate and Construction
Miller Thomson
Miller Thomson
Article

Holdback Deficiencies And Mortgage Priority: Court Of Appeal For Ontario Clarifies S. 78(2) Of The Construction Act

The Court of Appeal for Ontario has resolved a critical uncertainty in construction law regarding how holdback deficiencies should be calculated when owners fail to retain statutory holdbacks. The decision addresses whether contractors who have already been paid can claim additional priority over construction mortgages, and establishes important boundaries to prevent double recovery while balancing the interests of all parties in the construction pyramid.
CanadaReal Estate and Construction
Aird & Berlis LLP
Aird & Berlis LLP
Article

CBSA Anti-Dumping And Countervailing Duty Investigations: Truck And Bus Tires From China – What Producers, Exporters, And Importers Need To Know

Canada has initiated anti-dumping and countervailing duty investigations into truck and bus tires from China, with preliminary determinations expected by November 30, 2026. Producers, exporters, and importers—including companies from Korea, Japan, and Singapore with Chinese operations—face critical September and October deadlines to submit comprehensive responses or risk significantly higher duty rates.
CanadaInternational Law
Gowling WLG
Gowling WLG
Article

What Is The Hansa? From The Hanseatic League To Modern Cooperation Models

The term "Hansa" has re-emerged in modern geopolitical discourse, most notably through the 2026 Germany-Norway defence cooperation framework. This article examines how the principles of the medieval Hanseatic League—flexible coordination, shared standards, and mutual benefit without centralization—are being adapted to address contemporary challenges in defence, security, and cross-border collaboration.
GlobalInternational Law
Gowling WLG
Gowling WLG
Article

Peptides In Canada: Regulatory Reality Is Catching Up With The Hype

Health Canada's recent enforcement action against unauthorized injectable peptides signals a regulatory shift that wellness companies cannot afford to ignore. While peptides dominate influencer marketing and online wellness spaces, their legal status in Canada depends on factors far more complex than social media trends suggest. Understanding how route of administration, therapeutic claims, and market authorization intersect is now critical for compliance.
CanadaConsumer Protection
Gowling WLG
Gowling WLG
Article

The Warranty Of Good Working Order: New Québec Consumer Protection Regulation Takes Effect October 5, 2026

Starting October 5, 2026, Québec will introduce a new statutory warranty of good working order for consumer goods such as appliances and electronics, with minimum warranty periods ranging from 3 to 6 years. The legislation imposes disclosure obligations on manufacturers and merchants while prohibiting any attempts to exclude or limit this warranty. Businesses operating in Québec must adapt their practices to comply with these consumer protection requirements or face potential compliance issues.
CanadaConsumer Protection
Gowling WLG
Gowling WLG
Article

Canadian Product Stewardship And EPR: 2026 Summer Update

Canadian governments and producer-responsibility organizations are refining extended producer responsibility programs across the country, affecting packaging, batteries, electronics, and hazardous products. Recent regulatory changes include expanded collection obligations, adjusted compliance timelines, and new enforcement measures, with significant developments in British Columbia, Alberta, Saskatchewan, Manitoba, Ontario, Quebec, and Atlantic provinces.
CanadaEnvironment
Gowling WLG
Gowling WLG